TITLE

Tough to avoid immediate harm

AUTHOR(S)
Parvin, Cordell
PUB. DATE
August 2001
SOURCE
Roads & Bridges;Aug2001, Vol. 38 Issue 8, p14
SOURCE TYPE
Periodical
DOC. TYPE
Article
ABSTRACT
Reports the effects of 'No Damage for Delay' clause on owner and contractor relationship in Broward County, Florida. Lawsuit filed by Triple R Paving Inc. against the county for delay damages; Causes of the delays; Decision of the court on the delay damages claim.
ACCESSION #
5087437

 

Related Articles

  • Withdrawal fails to stave off cost award.  // Planning (14672073);5/28/2010, Issue 1870, p19 

    The article discusses a court case wherein the decision of the city council to withdraw its objections to the appellants' proposal to discharge three clauses in an obligation agreed in 1995, relative to the permission for residential development, has not saved it from a full award of costs in...

  • What's New in European Arbitration? Van Houtte, Vera; Wilske, Stephan; Young, Michael // Dispute Resolution Journal;May-Jul2007, Vol. 62 Issue 2, p9 

    This article presents a number of incidents pertaining to arbitration throughout Europe and Great Britain. The English Court of Appeal held that arbitrators should decide whether a contract between two parties is valid, unless that which makes it invalid is directly related to the arbitration...

  • Decisions, decisions, decisions. Jennings, Dick // Supply Management;12/11/2008, Vol. 13 Issue 25, p26 

    The article discusses legal developments in 2008 involving public procurement in Great Britain. The decision in the case "Alan Auld Associates v. Rick Pollard Associates" was important for purchasing companies that are making late payment. The "M&J Polymers v. Imerys Minerals" was influential...

  • IF CLAUSE DOESN'T SHIFT RISK, IT'S NOT PAY-IF-PAID.  // Construction Claims Monthly;Mar2013, Vol. 35 Issue 3, p17 

    The article cites court decisions on cases about pay-if-paid versus pay-when-paid clauses for construction projects. Based on the Court of Appeals of Ohio, parties need to clearly state their intent to shift risk of owner's non-payment from contractor to subcontractor to be considered...

  • How to Hold a Contractor to His Contract. Jeffries, Alexis // Money;Sep2008, Vol. 37 Issue 9, p63 

    The article provides an answer to a question of how to hold a contractor to their agreement.

  • Make sure repairs are in order. Parvin, Cordell // Roads & Bridges;Jun2002, Vol. 40 Issue 6, p16 

    Reports on the rejection by the Supreme Court of New York of a contractor's claim for compensation for additional work and costs. Details of the lawsuit brought by D. A. Elia Construction Corp. against the New York State Thruway Authority (NYSTA); Importance for contractors of understanding...

  • Skywater contractors vow to fight on. Brown, Hal // Burnet Bulletin (Texas);4/8/2009, Vol. 137 Issue 14, p20A 

    The article discusses a court case wherein several contractors filed a lawsuit to recover debts from the Skywater Over Horseshoe Bay in Austin, Texas.

  • SCIENCE AND RELIGION TWENTY YEARS AFTER MCLEAN V. ARKANSAS: EVOLUTION, PUBLIC EDUCATION, AND THE NEW CHALLENGE OF INTELLIGENT DESIGN. Beckwith, Francis J. // Harvard Journal of Law & Public Policy;Spring2003, Vol. 26 Issue 2, p455 

    Argues that the reasoning on the court case McLean versus Arkansas is not applicable to the question of whether a public school runs afoul of the Establishment Clause if it permits or requires the teaching of Intelligent Design. Scholarly support for Intelligent Design; Application of specified...

  • OF "PURPOSES NOT PROHIBITED": NEW FEDERAL RULE OF EVIDENCE 408(B). Collins, Gregory B.; Halaby, Andrew F. // Creighton Law Review;Jun2007, Vol. 40 Issue 4, p679 

    The article discusses how courts generally have applied the "another purpose" clause that is embodied in the "Permissible Uses" provision of Federal Rule of Evidence 408(b) in the U.S. It suggests that if properly applied, an expansive genus of compromise evidence must qualify for admission...

Share

Read the Article

Courtesy of THE LIBRARY OF VIRGINIA

Sorry, but this item is not currently available from your library.

Try another library?
Sign out of this library

Other Topics